HVAC Improvements (Phase 1) - To provide HVAC improvements (Phase 1) at a Judicial Branch location in Waterbury, Connecticut.

PROJECT MANUAL
APC PHASE 1 IMPROVEMENTS
AT
WATERBURY SUPERIOR COURT
400 GRAND STREET
WATERBURY, CONNECTICUT 06702
HON. RAHEEM L. MULLINS HON. ELIZABETH A. BOZZUTO
CHIEF JUSTICE CHIEF COURT ADMINISTRATOR
STATE OF CONNECTICUT
JUDICIAL BRANCH FACILITIES
90 WASHINGTON STREET
HARTFORD, CONNECTICUT 06106
Judicial Branch PN# JB25-017
ENGINEER:
H. F. Lenz
Engineer's PN# 2025-1648.01
January 12, 2026

SEALS PAGE
SECTION 00 0105
PAGE 1 of 1
SECTION 00 0105 - SEALS PAGE
ENGINEER:
H. F. Lenz
Architect Professional Certi- Civil Engineer Professional
fication: Certification:
I hereby certify that these I hereby certify that these
documents were prepared or documents were prepared or
approved by me and that I am approved by me and that I am a
a duly registered Architect. duly registered Professional
Engineer.
(Print Consultant Name) (Print Consultant Name)
License No. License No.
(Seal and Signature) (Seal and Signature)
Expiration Date Expiration Date
Structural Engineer Profes- Electrical Engineer Profes-
sional Certification: sional Certification:
I hereby certify that these I hereby certify that these
documents were prepared or documents were prepared or
approved by me and that I am approved by me and that I am a
a duly registered Professional duly registered Professional
Engineer. Engineer.
Scott Kraynak
(Print Consultant Name) (Print Consultant Name)
31314
License No. License No.
(Seal and Signature) (Seal and Signature) 01/31/2026
Expiration Date Expiration Date
Mechanical Engineer Profes- Fire-Protection Engineer
sional Certification: Professional Certification:
I hereby certify that these I hereby certify that these
documents were prepared or documents were prepared or
approved by me and that I am approved by me and that I am a
a duly registered Professional duly registered Professional
Engineer. Engineer.
Scott Kraynak
(Print Consultant Name) (Print Consultant Name)
31314
License No. License No.
(Seal and Signature) 01/31/2026 (Seal and Signature)
Expiration Date Expiration Date
END OF SECTION 00 0105
JUDICIAL BRANCH
H. F. Lenz APC PHASE 1 IMPROVEMENTS
2025-1648.01 JB25-017

TABLE OF CONTENTS
SECTION 00 0110
PAGE 1 of 2
SECTION 00 0110 - TABLE OF CONTENTS
Section No. Title Page Count Not Used
00 00 00 Project Manual Cover 1
00 01 05 Seals Page 1
00 01 10 Table of Contents 2
00 01 15 List of Drawing Sheets 1
00 01 20 Project Team List 1
DIVISION 01 GENERAL REQUIREMENTS
01 10 00 Summary of Work 5
01 21 00 Allowances 3
01 22 00 Unit Prices - X
01 23 00 Alternates - X
01 25 00 Substitution Procedures 4
01 26 00 Contract Modification Procedures 3
01 29 00 Payment Procedures 5
01 31 00 Project Management and Coordination 10
01 32 00 Construction Progress Documentation 7
01 32 10 Photographic Documentation 3
01 33 00 Submittal Procedure 8
01 35 16 Alteration Project Procedures 6
01 40 00 Quality Requirements 7
01 40 01 Statement of Special Inspections - X
01 50 00 Temporary Facilities and Controls 10
01 60 00 Product Requirements 7
01 73 00 Execution 10
01 77 00 Closeout Procedures 6
01 78 23 Operation and Maintenance Data 9
01 78 39 Project Record Documents 4
DIVISION 02 EXISTING CONDITIONS
02 41 19 Selective Demolition 5
JUDICIAL BRANCH
H. F. Lenz APC PHASE 1 IMPROVEMENTS
2025-1648.01 JB25-017

TABLE OF CONTENTS
SECTION 00 0110
PAGE 2 of 2
DIVISION 07
THERMAL AND MOISTURE PROTECTION
07 84 13 Penetration Firestopping 6
07 84 43 Joint Firestopping 5
07 92 00 Joint Sealants 6
DIVISION 23 - HVAC
23 05 00 Common Work Results for HVAC 67
23 05 13 Common Motor Requirements HVAC Equipment 7
23 05 16 Expansion Fittings and Loops for HVAC Piping 14
23 05 19 Meters and Gages for HVAC Piping 8
23 05 29 Hangers & Supports HVAC Piping Ducts & Equipment 20
23 05 48 Vibration Controls for HVAC 14
23 05 53 Identification for HVAC 8
23 05 93 Testing Adjusting and Balancing for HVAC 46
23 07 19 HVAC Piping Insulation 23
23 08 00 Commissioning for HVAC and Plumbing 13
23 09 00 Instrumentation and Control for HVAC 116
23 23 00 Refrigerant Piping 15
23 67 00 Variable Frequency Motor Controllers or Drives 15
23 81 23 Computer Room Air Conditioners and Condensers 13
DIVISION 26 ELECTRICAL
26 05 00 Common Work Results for Electrical 34
26 05 19 Low Voltage Electrical Power Conductors Cables 7
26 05 26 Grounding and Bonding for Electrical 5
26 05 29 Hangers and Supports for Electrical 7
26 05 33 Raceways and Boxes for Electrical 12
26 05 44 Sleeves and Sleeve Seals for Electrical 4
26 05 53 Identification for Electrical 5
26 27 26 Wiring Devices 9
26 28 16 Enclosed Switches and Circuit Breakers 4
END OF SECTION 00 0110
JUDICIAL BRANCH
H. F. Lenz APC PHASE 1 IMPROVEMENTS
2025-1648.01 JB25-017

DRAWING LIST
SECTION 00 0115
PAGE 1 of 1
SECTION 00 0115 - LIST OF DRAWING SHEETS
GENERAL PROJECT INFORMATION
Cover Sheet
PLUMBING
P201 Data Center Floor Plans Demo and New Work Plumbing
MECHANICAL
M001 General Notes, Symbols Mechanical
M002 Abbreviations Mechanical
M101 Ground and Data Center Floor Plans Demolition Mechanical
M201 Ground and Data Center Floor Plans New Work Mechanical
M601 Details Mechanical
M701 Schedules Mechanical
ELECTRICAL
E001 Legend, Abbreviations, and General Notes Electrical
E101 Ground / Second Floor Plans Demolition Electrical
E201 Ground / Second Floor Plans New Work Electrical
E701 Panel Schedules
END OF SECTION 00 0115
JUDICIAL BRANCH
H. F. Lenz APC PHASE 1 IMPROVEMENTS
2025-1648.01 JB25-017

TEAM LIST
SECTION 00 0120
PAGE 1 of 1
SECTION 00 0120 -PROJECT TEAM LIST
PRIME CONSULTANT
ENGINEER:
H. F. Lenz
101 Centerpoint Dr
Suite 237
Middletown, CT 06457
Project Contact:
Scott Kraynak, PE
skraynak@hflenz.com
(860) 316-2124
END OF SECTION 00 0120
JUDICIAL BRANCH
H. F. Lenz APC PHASE 1 IMPROVEMENTS
2025-1648.01 JB25-017

SUMMARY
SECTION 01 1000
PAGE 1 of 5
SECTION 01 1000 - SUMMARY
PART ONE - GENERAL
1.1 RELATED DOCUMENTS
A. Drawings and general provisions of the Contract, including General and Supplementary
Conditions and other Division 01 Specification Sections, apply to this Section.
1.2 SUMMARY
A. Section Includes:
1. Project information.
2. Work covered by Contract Documents.
3. Contractor's use of site and premises.
4. Coordination with occupants.
5. Work restrictions.
6. Specification and Drawing conventions.
7. Miscellaneous provisions.
B. Related Requirements:
1. Section 017300 "Execution" for coordination of Owner-installed products.
1.3 PROJECT INFORMATION
A. Project Identification:
1. APC Phase 1 Improvements
2. JB25-017
3. 400 Grand Street, Waterbury, CT 06702
B. Owner: State of Connecticut, Judicial Branch, Office of the Chief Court Administrator,
90 Washington Street, Hartford, CT 06106.
1. Owner's Representative:
a) Brian A. Dillon
Deputy Director
Judicial Branch Facilities
90 Washington Street
Hartford, CT 06106
Office: 860-706-5272
Cell: 860-549-2731
brian.dillon@jud.ct.gov
JUDICIAL BRANCH
H. F. Lenz APC PHASE 1 IMPROVEMENTS
2025-1648.01 JB25-017

SUMMARY
SECTION 01 1000
PAGE 2 of 5
C. Engineer: H. F. Lenz
1. Engineer's Representative: Scott Kraynak, 860.316.2124
1.4 WORK COVERED BY CONTRACT DOCUMENTS
A. The Work of Project is defined by the Contract Documents and includes, but is not
limited to, the following:
1. Disconnection and removal of existing indoor CRAC units, with in-kind
replacement of units.
2. Disconnection and removal of existing outdoor units, with installation of new in
same locations.
3. Disconnection and removal of existing refrigerant lines, with installation of new.
4. Furnish and install of condensate piping.
5. Electrical scope of work, including disconnect and removal of existing HVAC
circuits, and installation of new.
1.5 WORK SEQUENCE
A. Construct the Work in one single phase.
B. Mobilization
1. Project shall mobilize, and construction started no later than fourteen (14)
calendar days after issuance of a Purchase Order.
C. Submittals
1. The following shall be submitted at the earliest possible date, but no later than
seven (7) calendar days from issuance of a "Purchase Order".
a. Site Logistics Plan
b. Phasing/Sequence Plan
c. Contractor's Construction Schedule
d. Submittal Log
e. Schedule of Values
f. Key Personnel and Contact Information
g. Subcontract List
2. Remaining project submittals shall start no later than seven (7) calendar days
from issuance of a Purchase Order, including but not limited to:
a. Project/Site Safety Plan
b. Product/Material submittals
D. Closeout
JUDICIAL BRANCH
H. F. Lenz APC PHASE 1 IMPROVEMENTS
2025-1648.01 JB25-017

SUMMARY
SECTION 01 1000
PAGE 3 of 5
1. Closeout shall be completed within 30 calendar days from substantial
completion.
E. Before commencing Work of each phase, submit an updated copy of Contractor's construction
schedule, showing the sequence, commencement and completion dates for all phases of the
Work.
1.6 CONTRACTOR'S USE OF SITE AND PREMISES
A. Limits on Use of Site: Limit use of Project site to Work in areas indicated, and to loading
dock for removal of all construction related materials. Do not disturb portions of Project
site beyond areas in which the Work is indicated.
1. Limits on Use of Site: Confine construction operations to scope of work areas
and loading dock.
2. Driveways, Walkways and Entrances: Keep driveways, loading areas, and
entrances serving premises clear and available to Owner, Owner's employees,
and emergency vehicles at all times. Do not use these areas for parking or for
storage of materials.
a. Schedule deliveries to minimize use of driveways and entrances by
construction operations.
b. Schedule deliveries to minimize space and time requirements for storage
of materials and equipment on-site.
B. Condition of Existing Building: Maintain portions of existing building affected by
construction operations in a weathertight condition throughout construction period.
Repair damage caused by construction operations.
C. Condition of Existing Grounds: Maintain portions of existing grounds, landscaping, and
hardscaping affected by construction operations throughout construction period. Repair
damage caused by construction operations.
1.7 COORDINATION WITH OCCUPANTS
A. Full Owner Occupancy: Owner will occupy Project site and existing building during
entire construction period. Cooperate with Owner during construction operations to
minimize conflicts and facilitate Owner usage. Perform the Work so as not to interfere
with Owner's day-to-day operations. Maintain existing exits unless otherwise indicated.
1. Maintain access to existing walkways, corridors, and other adjacent occupied or
used facilities. Do not close or obstruct walkways, corridors, or other occupied or
used facilities without written permission from Owner and approval of authorities
having jurisdiction.
2. Notify Owner not less than 72 hours in advance of activities that will affect
Owner's operations.
JUDICIAL BRANCH
H. F. Lenz APC PHASE 1 IMPROVEMENTS
2025-1648.01 JB25-017

SUMMARY
SECTION 01 1000
PAGE 4 of 5
1.8 WORK RESTRICTIONS
A. Comply with restrictions on construction operations.
1. Comply with limitations on use of public streets, Work on public streets, rights of
way, and other requirements of authorities having jurisdiction.
B. On-Site Work Hours: Limit Work to between 7 a.m. to 5 p.m., Monday through Friday,
unless otherwise indicated. Work hours may be modified to meet Project requirements if
approved by Owner and authorities having jurisdiction.
1. Weekend Hours: Weekend Hours: 9 a.m. to 4 a.m.
C. Owner reserves the right to stop Work if it becomes disruptive to the daily
business/operation of the Court, court operations facility, and/or detention center.
Disruptive work must be completed outside of normal business hours at no cost to the
Owner.
D. Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by
Owner or others unless permitted under the following conditions and then only after
arranging for temporary utility services according to requirements indicated:
1. Notify Owner not less than four days in advance of proposed utility interruptions.
2. Obtain Owner's written permission before proceeding with utility interruptions.
E. Noise, Vibration, Dust, and Odors: Coordinate operations that may result in high levels of
noise and vibration, dust, odors, or other disruption to Owner occupancy with Owner.
1. Notify Engineer and Owner not less than two days in advance of proposed
disruptive operations.
2. Obtain Owner's written permission before proceeding with disruptive operations.
F. Smoking and Controlled Substance Restrictions: Use of tobacco products, alcoholic
beverages, and other controlled substances is not permitted.
G. Employee Identification: Provide identification tags and/or company branded clothing for
Contractor personnel working on Project site. Require personnel to use these at all times.
H. Employee Screening: Comply with Owner's requirements for drug and screening of
Contractor personnel working on Project site.
I. Contractor's personnel shall sign in/out daily with Owner representatives.
1.9 SPECIFICATION AND DRAWING CONVENTIONS
A. Specification Content: The Specifications use certain conventions for the style of
language and the intended meaning of certain terms, words, and phrases when used in
particular situations. These conventions are as follows:
JUDICIAL BRANCH
H. F. Lenz APC PHASE 1 IMPROVEMENTS
2025-1648.01 JB25-017