Hampstead Library Construction Services

Solicitation Number

473-ITB # 26-408

Department

Status Reason

Open

Opening Date

2025-12-18T15:00:00.0000000

Posted Date

2025-11-10T21:31:07.0000000Z

Commodity Code

Mandatory Conference/Site Visit

2025-11-20T05:00:00.0000000Z

Special Instructions

Solicitation Type

Select RFP IFB RFI

Owner

Description

ADVERTISEMENT FOR BIDS Sealed proposals will be received until 3:00 p.m. on Thursday, December 18, 2025, at which time they will be publicly opened and read aloud in the boardroom of the Pender County Government Center, 805 S. Walker Street, Burgaw, NC 28425. Submit sealed proposals to the following addresses: By Mail: Pender County, Attention: Trisha Newton, PO Box 1578, Burgaw, NC 28425 By UPS/FedEx/Courier: Pender County, Attention: Trisha Newton, 805 S. Walker Street, Burgaw, NC 28425 Clearly mark outside of package with general contractor’s name, license number, and “ITB # 26-408 Hampstead Library Construction Services”. A 5% bid bond is required, and shall be in a separate envelope from the sealed proposal. The contract shall be Single Prime. The work includes construction of a new 20,000 sf library and associated site improvements. Building construction: New work includes wood structure, masonry veneer, building insulation, interior painting, carpet, resilient and tile flooring, and acoustical tile ceilings. The work also includes plumbing, mechanical, electrical, and fire sprinkler. MINORITY BUSINESSES: Pender County encourages all businesses, including M/WBE, HUB, minority, and women-owned businesses to respond to all Invitations to Bid. An open pre-bid conference will be held for all interested bidders on November 20, 2025 at 2:00 p.m. in the auditorium at Pender County Hampstead Annex, 15060 US-17, Hampstead, NC 28443. The meeting will address project specific questions, issues, bidding procedures, and bid forms. The project site is adjacent to Pender County Hampstead Annex and is available at any time for all contractors and sub-contractors. Additional information and Addenda will be made available to the public by email or on the Architect’s website. The Contractor is responsible for ensuring that their contact information (phone & email) is correct and on file with the person designated below. Requests for substitution must be submitted in writing to the Architect by 5:00 p.m. on December 8, 2025. Requests for clarification or interpretation must be submitted in writing to the Architect by 5:00 p.m. on December 11, 2025. See contact info below. Electronic Contract Documents may be obtained by contacting the Architect, or visiting the architect’s website; s2a3.com/contractors/. No partial sets of the Contract Documents will be issued. Architect Contact: Scott Spike (910) 762-0892 scott@s2a3.com Sawyer Sherwood & Associate 124 Market Street, Wilmington, NC 28401 Pender County reserves the unqualified right to reject any and all proposals. Contractors must be properly licensed. Additional instructions to bidders are included in the Contract Documents. In order to be deemed responsive, the bidder must exemplify the skill, judgment, integrity, sufficient financial resources, and ability necessary to the faithful performance of the construction contract. The bidder’s Financial Statements may be requested by the County.

Attachments