Constructing Franklin County Emergency Operations Center

Agency:	Franklin County Courthouse Annex
State:	Florida
Type of Government:	State & Local
NAICS Category:	541611 - Administrative Management and General Management Consulting Services 541618 - Other Management Consulting Services 541690 - Other Scientific and Technical Consulting Services
Posted Date:	Aug 3, 2026
Due Date:	Oct 6, 2026
Original Source:	Please Login to View Page
Contact information:	Please Login to View Page
Bid Documents:	Please Login to View Page

Description

Title	End date
Constructing Franklin County Emergency Operations Center	October 6, 2026	Download

FRANKLIN COUNTY

EMERGENCY OPERATIONS CENTER

PROJECT #50186052

NOTICE TO RECEIVE SEALED BIDS

The Franklin County Board of County Commissioners will receive sealed bids from any qualified person,

company or corporation interested in constructing:

FRANKLIN COUNTY EMERGENCY OPERATIONS CENTER

The proposed project is located in Franklin County, Florida and consists of constructing a new Emergency

Operations Center along with asphalt paving, sidewalks, underground utilities, stormwater facilities and

other appurtenances.

Plans and specifications can be obtained by contacting Shannon Renfro at srenfro@dewberry.com,

Dewberry Engineers, Inc., 324 Marina Drive, Port St. Joe, FL 32456. There is no charge for electronic

plans. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.

Completion date for this project will be 365 days from the date of the Notice to Proceed presented to the

successful bidder. Liquidated damages for failure to complete the project on the specified date will be set

at $500.00 per day.

Please indicate on the envelope that this is a sealed bid, for “FRANKLIN COUNTY EMERGENCY

OPERATIONS CENTER”.

Bids will be received until 4:00 p.m. eastern time, on Tuesday, October 6th, 2026, at the Franklin County

Clerk's Office, Franklin County Courthouse, 33 Market Street, Suite 203, Apalachicola, Florida 32320-

2317, and will be opened and read aloud on Wednesday, October 7th, 2026, at the County Commission

meeting held at the Fort Coombs Armory Convention Center, 66 4th Street, Apalachicola, FL 32320.

The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or

reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin

County. All bids shall remain firm for a period of sixty days after the opening.

A mandatory pre-bid meeting will be held on Friday, September 18th, 2026, at 10:00 a.m. at the Fort

Coombs Armory Convention Center, 66 4th Street, Apalachicola, FL 32320.

All bidders shall comply with all applicable State and local laws concerning licensing registration and

regulation of contractors doing business to the State of Florida.

If you have any questions, please email Josh Baxley at jbaxley@dewberry.com by Wednesday,

September 23rd, 2026, by 5:00 p.m.

ADVERTISEMENT FOR BIDS-00010

This page summarizes the opportunity, including an overview and a preview of the attached documents.

Get Government Bids Like This by Email Receive daily bid alerts that match your keywords, business categories, and target regions.