CR 67 Widening and Resurfacing Project Bid

Agency: Franklin County Courthouse Annex
State: Florida
Type of Government: State & Local
NAICS Category:
  • 237310 - Highway, Street, and Bridge Construction
Posted Date: Oct 15, 2020
Due Date: Nov 16, 2020
Bid Source: Please Login to View Page
Contact information: Please Login to View Page
Bid Documents: Please Login to View Page
title end date
CR 67 Widening and Resurfacing Project Bid November 16, 2020 Download

Attachment Preview

PROJECT # 50082816
The Franklin County Board of County Commissioners will receive sealed bids from any qualified person,
company or corporation interested in constructing:
FPID NO. 440644-1-34-01
Project is located in Franklin County, Florida and consists of approximately 6.08 miles of widening and
resurfacing, striping, signs, minor drainage improvements, and grassing along CR 67 in Carrabelle, FL.
Plans and specifications can be obtained by contacting Cortni Bankston, Administrative Assistant, at or 850-653-9783 x-180. The bid must conform to Section 287.133(3)
Florida Statutes, on public entity crimes.
All bidders shall be FDOT qualified per Section 2-1 of the FDOT Standard Specifications for Road and
Bridge Constructions, latest edition in the following work classes: Grading, Drainage, Flexible Paving, and
Hot Plant mix-Bituminous Course.
Completion date for this project will be 180 days from the date of the Notice to Proceed presented to the
successful bidder. Liquidated damages for failure to complete the project on the specified date will be set
at $750.00 per day.
Please indicate on the envelope that this is a sealed bid, for “CR 67 Widening & Resurfacing Project”.
Bids will be received until 4:30 p.m. eastern time, on Monday, November 16, 2020, at the Franklin
County Clerk's Office, Franklin County Courthouse, 33 Market Street, Suite 203, Apalachicola, Florida
32320-2317, and will be opened and read aloud on Tuesday, November 17, 2020, at the County
Commission meeting at 34 Forbes Street, Apalachicola, FL.
The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or
reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin
County. All bids shall remain firm for a period of sixty days after the opening.
All bidders shall comply with all applicable State and local laws concerning licensing registration and
regulation of contractors doing business to the State of Florida.
All technical questions must be addressed in writing and emailed to Cortni Bankston at no later than November 6, 2020.

Sign-up for a Free Trial, Government Bid Alerts

With Free Trial, you can:

You will have a full access to bids, website, and receive daily bid report via email and web.

Try One Week FREE Now

See Also

Solicitation #: B200475BJB Project Name: Yellow Fever Creek Hydrologic Restoration and Gator Slough

Lee County

Bid Due: 11/23/2020

Bid number Title Agency Location End date Bid end Tab ITBC 2020-040 Lowson

City of Delray Beach

Bid Due: 11/16/2020

Form Details (Abstract): RFQ 20287 Status Active Abstract Agency Name Hillsborough County Event

Hillsborough County

Bid Due: 11/13/2020

092-20 (IFB) 5th St W - Imeson Rd to Melson Ave - Trans


Bid Due: 11/17/2020